Terms & Conditions

1. Acceptance of Terms & Construction Scope

By accessing, browsing, interacting with calculators, or submitting construction enquiries via this website operated by GG Construction Co. (“the Company”, “we”, “us”), you enter into a legally enforceable agreement governed by these Terms and Conditions under the Indian Contract Act, 1872.

Our business activity is strictly focused on building construction: residential homes, builder floors, neighborhood retail shops, small offices, and structural renovations up to approximately 4–5 floors across Delhi NCR (including Rohini, Pitampura, and surrounding Delhi sectors). We do not undertake large infrastructure, high-rise multi-tower developments, or government highway projects.

2. Nature of Preliminary Estimates & Absolute Non-Reliance

All cost simulations, rate ranges, per-square-foot projections, stage breakdowns, and timelines generated via the “Get a Quote” form, interactive calculators, or telephone discussions represent preliminary, non-binding budgetary approximations for conceptual planning only.

• No Commercial Offer or Tender: Online estimates do not constitute a formal commercial offer, legal tender, architectural guarantee, or fixed-rate bid. No contractor-client or engineering fiduciary relationship is established solely through website usage.
• Market Volatility & Commodity Price Shifts: Estimates are subject to Delhi NCR regional market variations in cement, primary TMT steel rebar (Fe 500D), sand, aggregate, brick/AAC block pricing, and municipal labor rates until an agreement is formally executed.
• Prerequisites for Binding Obligations: Binding contractual commitments arise exclusively upon:

  1. Physical on-site plot dimension and soil compaction verification.
  2. Inspection and approval of sanctioned architectural drawings and structural layouts.
  3. Mutual execution of a written, stamped legal construction contract with defined milestone deliverables and stage sign-offs.

3. Intellectual Property & Anti-Scraping Protection

All intellectual property, proprietary assets, and content on this website are the sole exclusive property of GG Construction Co. and protected under the Indian Copyright Act, 1957, the Trade Marks Act, 1999, and international intellectual property treaties.

• Anti-Poaching of Portfolio Images: The display of our executed residential projects, builder floors, or on-site images as one's own portfolio or promotional collateral constitutes fraudulent commercial misrepresentation and copyright infringement.
• Legal Recourse & Injunctive Relief: Any unauthorized scraping, bot harvesting, or trademark/copyright infringement will trigger immediate civil injunction proceedings, claims for liquidated commercial damages, and criminal prosecution under Sections 43 and 66 of the Information Technology Act, 2000.

4. Structural Standards & Municipal Clearances

All physical structural works contracted with GG Construction Co. conform to Bureau of Indian Standards specifications, specifically IS 456 (Code of Practice for Plain and Reinforced Concrete), IS 1905 for masonry, and associated civil construction engineering standards.

• Joint Milestone Verification: Site milestones (plinth beam, RCC column casting, slab pours, masonry, plastering) require joint inspection and written sign-off between the property owner and our on-site civil supervisor before advancing to subsequent stages.
• Statutory Approvals & Sanctions: Unless explicitly included within a written scope of contract, the property owner remains solely responsible for obtaining municipal building sanction plans, MCD / DDA approvals, water/sewer connections, and clear legal title to the construction plot.

5. Limitation of Liability & Damage Exclusions

To the fullest extent permissible under Indian law:

Our cumulative, aggregate legal liability arising from or related to any website usage or electronic communications shall be strictly capped at INR 1,000 (Rupees One Thousand only). Liability regarding active on-site construction is governed exclusively by the specific written executed construction contract.

6. User Warranties & Mutual Indemnification

You warrant and represent that:

• You possess the legal competence and lawful authority to submit information regarding the specified plot or building.
• Any architectural drawings or floor maps uploaded by you do not infringe any third party's copyright or trademark.
• You will not introduce viruses, automated scraping spiders, or malicious code to compromise our digital infrastructure.

You agree to defend, indemnify, and hold harmless GG Construction Co., its proprietor, staff, and representatives from any third-party claims, liabilities, losses, costs, or legal fees arising out of your violation of these Terms or unlawful website misuse.

7. Force Majeure & Delhi Environmental Halts (GRAP)

Building construction in the National Capital Territory of Delhi is strictly subject to environmental orders issued by the Commission for Air Quality Management (CAQM), the National Green Tribunal (NGT), and the Supreme Court of India.

GG Construction Co. shall not be held liable for project schedule delays, timeline extensions, or disruptions resulting from events beyond reasonable operational control, including:

• Mandatory seasonal construction bans enacted under Graded Response Action Plan (GRAP Stages III & IV) in Delhi NCR.
• Extreme monsoon waterlogging, seismic events, municipal stops, strikes, or raw material transportation blockades.

Project delivery milestones automatically extend by the equivalent duration of any statutory environmental halt without financial penalties.

8. Dispute Resolution & Sole Arbitration in Delhi

These Terms and any project communications shall be governed by, interpreted, and construed exclusively in accordance with the laws of the Republic of India.

• Mandatory Amicable Negotiation: Any disagreement, claim, or controversy arising out of these terms shall first be addressed through good-faith amicable negotiation between the parties within a 30-day period.
• Sole Arbitration: If unresolved amicably, the dispute shall be referred to binding arbitration conducted by a mutually agreed sole arbitrator in accordance with the Arbitration and Conciliation Act, 1996. The seat and venue of arbitration shall be New Delhi, India.
• Exclusive Court Jurisdiction: Subject to the arbitration clause, the competent civil courts located in Delhi, India, shall hold exclusive territorial jurisdiction.

9. Severability, Non-Waiver & Entire Agreement

If any provision of these Terms is determined to be unlawful, invalid, or unenforceable by an arbitrator or court of competent jurisdiction, that provision shall be severed without affecting the validity and enforceability of the remaining provisions.

Failure or delay by GG Construction Co. to enforce any right or covenant does not constitute a waiver of that right. These Terms constitute the complete understanding between you and the Company concerning website usage.